TERMS AND CONDITIONS
Agreement means the cover page, these terms and conditions and the credit application (where applicable).
Seller means Eden Roc Garage Doors.
Buyer means the purchaser of the product manufactured or services rendered by Eden Roc Garage Doors.
Payment Schedule means the amounts agreed to on the cover page or otherwise agreed to in writing.
Product means the products and/or services to be supplied by Eden Roc Garage Doors.
Any dates given by Eden Roc Garage Doors for delivery or installation are estimates only. If Eden Roc Garage Doors is unable to deliver or install by the given date, Eden Roc Garage Doors is not liable for any loss or damage arising out of the delay.
- Buyer may notify defects. If the buyer regards the product as defective, the buyer may make a complaint:
- by notifying Eden Roc Garage Doors in writing no later than 15 days after delivery of the product, and
- providing the original of this agreement to Eden Roc Garage Doors and
- providing proof of purchase by attaching an invoice
- Eden Roc Garage Doors may repair defects. Eden Roc Garage Doors must examine the notified defects within 30 days from the date of receipt of the complaint. If Eden Roc Garage Doors confirms that the product is defective, then Eden Roc Garage Doors may repair the product or, at its discretion, replace any defective product or parts thereof for a period of one year from the date of invoice. The buyer must pay for any service call made by Eden Roc Garage Doors when, in the reasonable opinion of Eden Roc Garage Doors, the call is made for the purpose of adjustment and not for the purpose of repairing the defect.
- Risk in the product passes to the buyer on delivery to the site, or to a nominated carrier for transportation to the site, or to a place or site nominated by the buyer or at the buyer’s discretion, and
- Risk in the product passes to the buyer whether or not the buyer is present at the time of delivery to sign a receipt for the product, and
- It is the buyer’s responsibility to ensure products are safely secured on his premises while awaiting installation by the Eden Roc Garage Doors installation team.
The buyer must ensure that the area required by Eden Roc Garage Doors for installation work is clear of obstructions and is in a safe and secure condition for the performance of the work.
If the buyer provides Eden Roc Garage Doors with details and measurements of floor levels, heights and openings and does not require Eden Roc Garage Doors to inspect the site and verify the measurements, then any error does not entitle the buyer to reject the product.
- Eden Roc Garage Doors responsibility for damage
Eden Roc Garage Doors must make good any loss or damage to the product or property of the buyer caused by Eden Roc Garage Doors or Eden Roc Garage Doors employees, agents of subcontractors.
- General Exceptions
The buyer releases Eden Roc Garage Doors from any claim or liability, including consequential loss or damage and loss of use and loss of profit, which is the result of delay, defective or faulty materials or workmanship, negligence or any act or omission by Eden Roc Garage Doors.
- Specific exceptions
Eden Roc Garage Doors is not liable for any loss or damage cause directly or indirectly by:
- operating a product by any device, electronic or otherwise, which was not supplied or installed by Eden Roc Garage Doors
- any masonry, rendered or other surfaces cracking or collapsing during or after the installation of the product
- any defect or deterioration of timber, including drying out after installation of the product
- any weakening or collapse of the structure to which the product is affixed occurring at any time after installation
- any damage to or deterioration in the condition of the product occurring after delivery and before installation.
If the product includes installation, Eden Roc Garage Door must remove from the site all plant and equipment and all rubbish and surplus material relating to the installation. All demolished and surplus material is the property of Eden Roc Garage Doors unless otherwise specified on the cover page.
Title in the product shall pass to the buyer upon payment for the product in full.
Subject to the statutory warranties Eden Roc Garage Doors warrants that new product will be free from defects in materials and workmanship, from the date of purchase, for periods as specified.
Roller Door: Domestic use – – 7/1 years (1 year on surface coating and locking mechanism) Industrial/Commercial use – 1 year
Sectional/Tilt Door: Domestic or Industrial/Commercial – 1 year
Motor: Depends on brand – see manufacturer’s warranty
Roller Door Motor: Depends on brand – see manufacturer’s warranty
Installation: (refer clause 14.c) below
- Correct Use: The warranties only apply to a unit used by the buyer correctly and reasonably and the product is maintained and serviced by the buyer as recommended by Eden Roc Garage Doors.
- Follow Instructions: The warranties only apply if the buyer observes any instructions or directions provided with the product.
- Installation by Eden Roc Garage Doors: The warranties cover, for a period of 12 months, defects in or malfunction of the product resulting from faulty installation of the product by Eden Roc Garage Doors. Eden Roc Garage Doors does not warrant product faults caused as a result of installation carried out by another contractor.
- Reasonable Repairs: The warranties only cover repairs in a manner Eden Roc Garage Doors considers reasonable including, if necessary, the touch-up of surface coatings
- Proven Defects: The warranties only apply to repairs of proven defects in materials and workmanship.
- Proof of Purchase date: The buyer must establish to the reasonable satisfaction of Eden Roc Garage Doors or such distributor, the date of purchase or installation (as the case may be).
- Environmental Conditions: The warranties do not cover damage to the surface coatings or the base materials of the unit caused by proximity to the seafront, or similar corrosive conditions.
- Events beyond the Control of Eden Roc Garage Doors: The warranties do not cover defects in or malfunction of a product due to an event or acts beyond the control of Eden Roc Garage Doors.
- Model Modifications: The warranties do not require Eden Roc Garage Doors to incorporate any modifications made to existing or future models of the product in products sold under these warranties.
- Labour and Materials: the warranty covers the cost of both the faulty component(s) and the labour involved in replacing/repairing the faulty component(s) but not travel expenses where the product is installed outside the metropolitan area.
Eden Roc Garage Doors obligations under these warranties are limited to those contained in this Clause 16.
The warranties above or any terms and conditions of this agreement shall only be applied to the extent permitted by the provisions of the Trade Practices Act 1974, or any terms and conditions or warranties expressed or implied by any relevant state act or territorial ordinance or by the general law.
The agreement for the supply of the product by Eden Roc Garage Doors to the buyer shall be governed by the law of the state or territory in which Eden Roc Garage Doors accepts the buyers order and Eden Roc Garage Doors and the buyer submit to the jurisdiction of the courts of that state or territory.